Last Updated: 2023-08-08
Welcome to Renova Contractors LLC. These Terms and Conditions ("Terms") govern your use of our website and services. By accessing or using our website, you agree to comply with and be bound by these Terms. If you do not agree to these Terms, please do not use our website or services.
By accessing, browsing, or using our website and services, you irrevocably agree to be bound by these Terms and Conditions. If you do not agree with any part of these Terms, you must immediately discontinue use of our website and services. Your continued use of the website and services will be deemed as acceptance of any changes to these Terms.
Renova Contractors LLC reserves the right, at its sole discretion, to modify or replace these Terms at any time without prior notice. It is your responsibility to review these Terms periodically. Continued use of our website or services after any such changes constitutes acceptance of those changes.
Renova Contractors LLC provides home renovation and contracting services, including but not limited to kitchen remodeling, bathroom remodeling, attic finishing, and general home improvement. All services are provided 'as is' and 'as available' and are subject to these Terms and any specific agreements between Renova Contractors LLC and the client. Renova Contractors LLC makes no warranties regarding the results, accuracy, or reliability of any services performed.
All estimates provided by Renova Contractors LLC are non-binding and are subject to change based on variables such as material costs, labor fluctuations, and scope adjustments. A formal contract will be executed prior to the commencement of any work, detailing the specific terms, scope, and costs. The contract must be signed by both parties before any work begins. Any modifications to the scope of work must be documented in a written change order and may result in additional costs and extended timelines.
Payments are due according to the payment schedule outlined in the contract. Renova Contractors LLC requires an initial deposit of at least 50% of the total contract amount before work commences. Subsequent payments are due upon reaching agreed-upon project milestones, with the final payment due immediately upon project completion. Non-payment or late payment will result in immediate suspension of work and may incur additional charges, including but not limited to interest, legal fees, and collection costs.
Late payments will incur a late fee of 1.5% per month on the outstanding balance or the maximum allowed by law, whichever is greater. If payment is not received within 10 days of the due date, Renova Contractors LLC reserves the right to halt all work until payment is made in full. If the client fails to make payment within 30 days, Renova Contractors LLC may terminate the contract and seek full payment for all completed work, materials, and any additional costs incurred.
All payments made to Renova Contractors LLC are non-refundable. In the event of a dispute, Renova Contractors LLC will make reasonable efforts to resolve the issue, but reserves the right to retain any payments made for work already completed, materials purchased, and any costs incurred. Clients waive any right to chargebacks or other forms of payment reversals.
The client is responsible for providing Renova Contractors LLC with unobstructed access to the property during agreed-upon working hours. The client must ensure that all necessary permits, approvals, and legal authorizations are secured before work commences, unless otherwise agreed upon in the contract. Delays caused by the client's failure to secure necessary permits or provide access may result in additional charges and extended project timelines.
The client is responsible for preparing the work area, which includes removing personal belongings, furniture, and any other obstructions. Renova Contractors LLC is not liable for damage to items that are not removed from the work area. The client acknowledges that construction work may cause unavoidable disturbances, and agrees to hold Renova Contractors LLC harmless for any inconvenience caused.
Renova Contractors LLC offers a limited warranty on workmanship for a period of 1 year from the date of project completion. This warranty is strictly limited to defects in workmanship and does not cover materials, normal wear and tear, or damage caused by misuse, neglect, or external factors. Any warranty claims must be submitted in writing within the warranty period. Renova Contractors LLC reserves the right to inspect and remedy any valid claims at its sole discretion.
Except as expressly provided in these Terms, all services are provided 'as is' and 'as available', without any warranties of any kind, either express or implied, including but not limited to warranties of merchantability, fitness for a particular purpose, and non-infringement. Renova Contractors LLC does not warrant that the services will meet the client's requirements, be uninterrupted, timely, secure, or error-free. The client assumes all risks associated with the use of the services.
To the maximum extent permitted by law, Renova Contractors LLC shall not be liable for any indirect, incidental, special, consequential, or punitive damages, including but not limited to loss of profits, data, or use, arising out of or in connection with the use of our services or website. The total liability of Renova Contractors LLC for any claims arising out of or related to these Terms or our services shall not exceed the amount paid by the client to Renova Contractors LLC in the 12 months preceding the claim. The client waives any right to seek damages beyond this limitation.
The client agrees to indemnify, defend, and hold harmless Renova Contractors LLC, its officers, directors, employees, agents, and affiliates from and against any and all claims, damages, losses, liabilities, costs, and expenses (including reasonable attorneys' fees) arising out of or related to the client's use of our website or services, the client's breach of these Terms, or the client's violation of any rights of a third party. This indemnification obligation survives the termination of these Terms and the completion of services.
Renova Contractors LLC reserves the right to terminate or suspend the client's access to our website and services at any time, without notice, for conduct that it believes violates these Terms, is harmful to its interests, or for any other reason at its sole discretion. Upon termination, the client must immediately cease all use of the services, and any outstanding balances owed to Renova Contractors LLC shall become immediately due and payable.
These Terms and any disputes arising out of or related to these Terms or our services shall be governed by and construed in accordance with the laws of the State of [Insert State], without regard to its conflict of law principles. The client agrees to submit to the exclusive jurisdiction of the courts located in [Insert County], [Insert State], for the resolution of any disputes. Any legal action or proceeding arising under these Terms must be brought within one year after the cause of action arises.
If any provision of these Terms is found to be invalid or unenforceable by a court of competent jurisdiction, such provision shall be enforced to the maximum extent permissible, and the remaining provisions of these Terms shall remain in full force and effect. The invalidity or unenforceability of any provision shall not affect the validity or enforceability of the remaining provisions.
These Terms, together with any other legal notices or agreements published by Renova Contractors LLC, constitute the entire agreement between the client and Renova Contractors LLC with respect to the use of our website and services, and supersede all prior or contemporaneous communications and proposals, whether oral or written, between the client and Renova Contractors LLC. No waiver of any provision of these Terms shall be deemed a further or continuing waiver of such provision or any other provision.
By using our website or services, the client acknowledges that they have read, understood, and agree to be bound by these Terms and Conditions.
